Us Code § 1499 - Liquidated damages withheld from contractors under chapter 37 of title 40
Full text of Us Code United States Code § 1499 — Liquidated damages withheld from contractors under chapter 37 of title 40, with citation guidance and answers to common questions.
§ 1499. Liquidated damages withheld from contractors under chapter 37 of title 40
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.
(June 25, 1948, ch. 646, 62 Stat. 942; Pub. L. 87–581, title II, §202(a), Aug. 13, 1962, 76 Stat. 360; Pub. L. 97–164, title I, §133(e)(1), (2)(A), Apr. 2, 1982, 96 Stat. 40, 41; Pub. L. 101–650, title III, §325(b)(7), Dec. 1, 1990, 104 Stat. 5121; Pub. L. 102–572, title IX, §902(a)(1), Oct. 29, 1992, 106 Stat. 4516; Pub. L. 107–217, §3(g)(3), Aug. 21, 2002, 116 Stat. 1299; Pub. L. 109–284, §4(2), Sept. 27, 2006, 120 Stat. 1211.)
Historical and Revision Notes
Based on section 324 of title 40, U.S.C., 1940 ed., Public Buildings, Property and Works (June 19, 1912, ch. 174, §1, 37 Stat. 137).
This section contains only the jurisdictional provision in the last clause of section 324 of title 40, U.S.C., 1940 ed.
Changes in phraseology were made.
Editorial Notes
Amendments
2006—Pub. L. 109–284 substituted "chapter 37 of title 40" for "Contract Work Hours and Safety Standards Act" in section catchline.
2002—Pub. L. 107–217 substituted "section 3703 of title 40" for "section 104 of the Contract Work Hours and Safety Standards Act".
1992—Pub. L. 102–572 substituted "United States Court of Federal Claims" for "United States Claims Court".
1990—Pub. L. 101–650 substituted "Hours and Safety Standards" for "Hours Standards" in text.
1982—Pub. L. 97–164 substituted "Contract Work Hours and Safety Standards Act" for "Contract Work Hours Standards Act" in section catchline and "United States Claims Court" for "Court of Claims" in text.
1962—Pub. L. 87–581 amended section generally, substituting "Liquidated damages withheld from contractors under Contract Work Hours Standards Act" for "Penalties imposed against contractors under eight hour law" in section catchline, and "liquidated damages withheld from a contractor or subcontractor under section 104 of the Contract Work Hours Standards Act" for "a penalty withheld from a contractor or subcontractor under section 324 of Title 40" in text.
Statutory Notes and Related Subsidiaries
Effective Date of 1992 Amendment
Amendment by Pub. L. 102–572 effective Oct. 29, 1992, see section 911 of Pub. L. 102–572, set out as a note under section 171 of this title.
Effective Date of 1982 Amendment
Amendment by Pub. L. 97–164 effective Oct. 1, 1982, see section 402 of Pub. L. 97–164, set out as a note under section 171 of this title.
Effective Date of 1962 Amendment
Amendment by Pub. L. 87–581 effective 60 days after Aug. 13, 1962, but shall not affect contracts existing or thereafter entered into pursuant to invitations for bids outstanding on Aug. 13, 1962, see section 204 of Pub. L. 87–581, Aug. 13, 1962, 76 Stat. 360.
Continued Jurisdiction Upon Claims Under Section 324 of Former Title 40
Pub. L. 87–581, title II, §202(b), Aug. 13, 1962, 76 Stat. 360, provided that the Court of Claims (now United States Court of Federal Claims) was to continue to have jurisdiction to render judgment upon certain claims for a penalty withheld from a contractor or subcontractor under section 324 of former Title 40, Public Buildings, Property, and Works, in connection with any contract subject to that section existing on the date sixty days after Aug. 13, 1962, or thereafter entered into pursuant to invitations for bids that were outstanding on Aug. 13, 1962.
About This Section
28 U.S.C. § 1499 is part of Title 28 of the United States Code. The United States Code is the official codification of federal statutes maintained by the Office of the Law Revision Counsel of the U.S. House of Representatives. Congress amends the Code through new public laws, which are eventually incorporated into the relevant title.
This section may be cited in legal writing as 28 U.S.C. § 1499. For the most current official text, including any recent amendments, use the official source links below. Do not rely on this page as the sole authority for legal citation or litigation.
How to Read This Statute
Statutes are organized by title, chapter, section, and subsection. Pay attention to words like "shall," "may," "and," and "or," because they determine whether a requirement is mandatory or permissive and whether multiple conditions must all be met. Historical notes and amendments often appear at the end of a section.
Using This Page
This page is intended for research and educational use. Lawyers, students, journalists, and compliance professionals can use it as a starting point, but should always verify the current text through an official government source before relying on it for legal advice, filings, or compliance decisions.