North Carolina § 1-50 - Six years.

§ 1-50. Six years.

Within six years an action - Repealed by Session Laws 1997-297, s. 1. Against an executor, administrator, collector, or guardian on his official bond, within six years after the auditing of his final account by the proper officer, and the filing of the audited account as required by law. For injury to any incorporeal hereditament. Against a corporation, or the holder of a certificate or duplicate certificate of stock in the corporation, on account of any dividend, either a cash or stock dividend, paid or allotted by the corporation to the holder of the certificate or duplicate certificate of stock in the corporation. No action to recover damages based upon or arising out of the defective or unsafe condition of an improvement to real property shall be brought more than six years from the later of the specific last act or omission of the defendant giving rise to the cause of action or substantial completion of the improvement. (5) a. No action to recover damages based upon or arising out of the defective or unsafe condition of an improvement to real property shall be brought more than six years from the later of the specific last act or omission of the defendant giving rise to the cause of action or substantial completion of the improvement. For purposes of this subdivision, an action based upon or arising out of the defective or unsafe condition of an improvement to real property includes: Actions to recover damages for breach of a contract to construct or repair an improvement to real property; Actions to recover damages for the negligent construction or repair of an improvement to real property; Actions to recover damages for personal injury, death or damage to property; Actions to recover damages for economic or monetary loss; Actions in contract or in tort or otherwise; Actions for contribution indemnification for damages sustained on account of an action described in this subdivision; Actions against a surety or guarantor of a defendant described in this subdivision; Actions brought against any current or prior owner of the real property or improvement, or against any other person having a current or prior interest therein; Actions against any person furnishing materials, or against any person who develops real property or who performs or furnishes the design, plans, specifications, surveying, supervision, testing or observation of construction, or construction of an improvement to real property, or a repair to an improvement to real property. For purposes of this subdivision, "substantial completion" means that degree of completion of a project, improvement or specified area or portion thereof (in accordance with the contract, as modified by any change orders agreed to by the parties) upon attainment of which the owner can use the same for the purpose for which it was intended. The date of substantial completion may be established by written agreement. The limitation prescribed by this subdivision shall not be asserted as a defense by any person in actual possession or control, as owner, tenant or otherwise, of the improvement at the time the defective or unsafe condition constitutes the proximate cause of the injury or death for which it is proposed to bring an action, in the event such person in actual possession or control either knew, or ought reasonably to have known, of the defective or unsafe condition. The limitation prescribed by this subdivision shall not be asserted as a defense by any person who shall have been guilty of fraud, or willful or wanton negligence in furnishing materials, in developing real property, in performing or furnishing the design, plans, specifications, surveying, supervision, testing or observation of construction, or construction of an improvement to real property, or a repair to an improvement to real property, or to a surety or guarantor of any of the foregoing persons, or to any person who shall wrongfully conceal any such fraud, or willful or wanton negligence. This subdivision prescribes an outside limitation of six years from the later of the specific last act or omission or substantial completion, within which the limitations prescribed by G.S. 1-52 and 1-53 continue to run. For purposes of the three-year limitation prescribed by G.S. 1-52, a cause of action based upon or arising out of the defective or unsafe condition of an improvement to real property shall not accrue until the injury, loss, defect or damage becomes apparent or ought reasonably to have become apparent to the claimant. However, as provided in this subdivision, no action may be brought more than six years from the later of the specific last act or omission or substantial completion. The limitation prescribed by this subdivision shall apply to the exclusion of G.S. 1-15(c), G.S. 1-52(16) and G.S. 1-47(2). Repealed by Session Laws 2009-420, s. 1, effective October 1, 2009, and applicable to causes of action that accrue on or after that date. Recodified as G.S. 1-47(6) by Session Laws 1995 (Regular Session, 1996), c. 742, s. 1. This section applies to actions brought by a private party and to actions brought by the State or a political subdivision of the State. History (C.C.P., s. 33; Code, s. 154; Rev., s. 393; C.S., s. 439; 1931, c. 169; 1963, c. 1030; 1979, c. 654, s. 2; 1981, c. 644, s. 1; 1991, c. 268, s. 2; 1995, c. 291, s. 1; 1995 (Reg. Sess., 1996), c. 742, s. 1(a); 1997-297, s. 1; 2009-420, s. 1.) Cross References. - For three-year limitation applicable to actions upon the official bond of a public officer, see now G.S. 1-52 (1a). For three-year limitation applicable to actions against sureties of executors, etc., on their principal's official bond, see G.S. 1-52(6) . As to bond of personal representative, see G.S. 28A-8-1 et seq. As to limitations period for unknown and certain other claims against a dissolved corporation, see G.S. 55-14-07 . As to product liability actions, see G.S. 99B-1 et seq. Legal Periodicals. - For survey of 1979 commercial law, see 58 N.C.L. Rev. 1290 (1980). For article, "North Carolina's New Products Liability Act: A Critical Analysis," see 16 Wake Forest L. Rev. 171 (1980). For article discussing product liability as affected by statutes of repose, see 61 N.C.L. Rev. 33 (1982). For survey of 1982 law on civil procedure, see 61 N.C.L. Rev. 991 (1983). For comment on the effect of Lamb v. Wedgewood S. Corp., 308 N.C. 419 , 302 S.E.2d 868 (1983), on future cases determining the constitutionality of subdivision (6) of this section, see 19 Wake Forest L. Rev. 1049 (1983). For note, "Wilder v. Amatex Corp.: A First Step Toward Ameliorating the Effect of Statutes of Repose on Plaintiffs with Delayed Manifestation Diseases," see 64 N.C.L. Rev. 416 (1986). For note on six year statutory bar to products liability actions, in light of Tetterton v. Long Manufacturing Co., 314 N.C. 44 , 332 S.E.2d 67 (1985), see 64 N.C.L. Rev. 1157 (1986). For survey of North Carolina construction law, with particular reference to statutes of limitation and repose, see 21 Wake Forest L. Rev. 633 (1986). For survey, "Contract Warranties and Remedies: A Comprehensive Survey of the Creation, Modification and Exclusion of Contract Warranties and Remedies for Attorneys and Contracting Professionals," see 14 Campbell L. Rev. 323 (1993). For note, "Do You Need 'Will Insurance'? Let the Testator Beware - Hargett v. Holland," see 21 N.C. Cent. L.J. 353 (1995).