California § 529.1 - In all actions in which the court has granted an injunction sought by any plainti

§ 529.1. In all actions in which the court has granted an injunction sought by any plainti

(a) In all actions in which the court has granted an injunction sought by any plaintiff to enjoin a construction project which has received all legally required licenses and permits, the defendant may apply to the court by noticed motion for an order requiring the plaintiff to furnish an undertaking as security for costs and any damages that may be incurred by the defendant by the conclusion of the action or proceeding as the result of a delay in the construction of the project. The motion shall be made on the grounds that there is no reasonable possibility that the plaintiff will obtain a judgment against the moving defendant and that the plaintiff will not suffer undue economic hardship by filing the undertaking. (b) If the court, after hearing, determines that the grounds for the motion have been established, the court shall order that the plaintiff file the undertaking in an amount specified in the court’s order as security for costs and damages of the defendant. The liability of the plaintiff pursuant to this section for the costs and damages of the defendant shall not exceed five hundred thousand dollars ($500,000). (c) As used in this section, a construction project includes, but is not restricted to, the construction, surveying, design, specifications, alteration, repair, improvement, maintenance, removal, or demolition of any building, highway, road, parking facility, bridge, railroad, airport, pier or dock, excavation or other structure, development or other improvement to real or personal property.